The URL can be used to link to this page

Home My WebLink AboutChange order #2 Dickerson Infrastructure 11463Change Order# I Purchase Order # Contractor: Address: 11463 CITY OF Sf]3ASTIAN HOME OF PELICAN ISLAND CHANGE ORDER FORM Project Name Project # Dickerson Infrastructure, Inc. 3122 North 25th Street Ft Pierce, FL 34946 Contact Name Contract Date Taxiway G Construction A2551 Mike Bryant August 12, 2025 By the signature affixed below, the City and the Contractor agree to the changes stipulated herein. Upon proper execution of this document, the Contractor is hereby notified to commence work. All changes stated below are hereby incorporated and made a part of the Contract identified above, and all the terms and conditions of said Contract are enjoined and in full force while executing the change(s) stipulated as follows: DESCRIPTION: This Change Order is being issued to accomplish the following: 1. Contract Amount Increase: Add $57,118.00 to address unsuitable subbase material encountered at the Phase 2 Taxiway G/B tie-in. Excavation revealed 8-12 inches of gray sand and an undetermined layer of decomposed organics ("muck"), creating unstable ground conditions. Work was halted pending the Engineer of Record's direction (see Exhibit A: RFI 0004 and Cost Breakdown). 2. Contract Time Extension: Extend the contract by fourteen (14) calendar days. Seven (7) days for City of Sebastian's scheduled closures (Nov 2025-Jan 2026, Exhibit B) and seven (7) days for additional work required at the Taxiway G/B tie-in. 3. uidated Damaoes Revision: Revise the schedule to combine Phases 1 and 2 and reflect the added calendar days (Exhibit C). A. Contract price prior to this change Net increase (decrease) resulting from this change New contract price including this change order 959,166.40 57,118.00 $1,016,284.40 B. Contract time prior to this change (number of days) 97 (211/2026) Net increase (decrease) resulting from this change (number of days) 14 days New completion date including this change 111 days (2/15/2026) AGREED: ENGINEER: DICKERSON INFRASTRUCTURE: ID 101W1. o'pMMPoMaM •MMN4�+M�Okewpmm �•nwry12A360]]]M ESL Flamed Jafarian, PE, ICE Date: 01 /12/2026 Procurement Division 6.AEil9�9�MESE.. MM•N•b+aq mbymlMflM1twn. M��✓Y �3.3436M]I AM FS] Mike Bryant, President Date: 01 /13/2026 1225 Main Street, Sebastian, FL 32958 Phone:772-388-8231 Page t of 7 Document ID: B5EE778A8DC7DA9C4FFFD479A848DEAA CITY OF SEBASTIAN: L'4K Brian Bent , City Manager Date: 'City, 6 ADorovals by City of Sebastian Staff. CM OF Sf)3AST1 kN HOME OF PELICAN ISLAND Catherine E esta, ing City Clerk Date: I 126 _ City Manager Authorization — a cumulative amount less than 15% of the contract price or $15,000. X City Council Authorization — a cumulative amount exceeds 15% of the contract price or $15,000. CITY COUNCIL MEETING: January 28, 2026 Project Manager 15 as to Scope of Work Procurement Manager K as to purchasing Finance is as to budget City Attorney �as to legal Procurement Division 1225 Main Street, Sebastian, FL 32958 Phone:772-388-8231 Page 2 of 7 Document ID: BSEE778A8DC7DA9C4FFFD479A848DEAA CITY Or Sfj3ASTj_APq HOME OF PELICAN ISLAND Exhibit A RFI 0004 and Cost Estimate Unforeseen Condition Unsuitable Subbase Material Replacement Procurement Division 1225 Main Street, Sebastian, FL 32958 Phone: 772-388-8231 Page 3 of 7 Document ID: B5EE778A8DC7DA9C4FFFD479A848DEAA REQUEST FOR INFORMATION (RFI) I RFI No: 0004 CONTRACT NO.: CONTRACT TITLE: PRIME CONTRACTOR: G3A50 Sebastian Municipal Airport, Taxiway Dickerson Infrastructure, Inc. G (Golf) Construction Project CONTRACTOR'S REQUEST FOR INFORMATION REQUESTED BY: DATE REQUESTED: POTENTIAL COST IMPACT: Yes Zephyr Zuccarelli 1 12/8/2025 1 POTENTIAL SCHEDULE IMPACT Yes SUBCONTRACTOR: RFI SUBJECT: Phase 2 Construction; Demolition of Phase 2; Taxiway G and Taxiway B (tie-in). Existing conditions (subbase) require assessment before proceeding. FEATURE OF WORK; Taxiway G (Golf) Construction SPECIFICATION SECTION: S-140; "Site Demolition", section 140-2.5 "Compaction of Existing Base and Subgrade", P-152; "Excavation, Subgrade and Embankment", and P- 154; "Subbase Course". INFORMATION REQUESTED: Requesting ICE -Engineer to address and advise how to proceed ASAP. Reference: Approved for Consmiction (AFC) Plans: Sheet C2.3. Specifications: S-140; "Site Demolition", section 140-2.5 "Compaction of Existing Base and Subgrade", P-152; "Excavation, Subgrade and Embankment", and P-154; "Subbase Course". Requesting the following Information: During Phase 2 construction (demolition activities, 12/8/25) base rock was removed, revealing subbase. (Location is the Northwest radius at the Taxiway G and Taxiway B tie-in area.) Contractor encountered existing conditions of subbase different than expected, causing a STOP in WORK (questioning attitude prompted by contractor). Existing conditions as follows: Subbase of 8-12 inches of gray sand with (undetermined amount; 1-3 feet possible) sub -layer of "muck" (decomposed organics/spongy peatmoss layer at water table). Ground unstable, "pumping and moving" under equipment load. RFI 0004 was prompted by ICE -Engineers to begin the process of determination regarding how to proceed with demolition and construction activities for Phase 2. We appreciate your prompt response/acknowledgement of this RFI, as this clarification/correction is essential for maintaining construction alignment with project specifications. CONTRACTOR'S RECOMMENDATION: RFI response. Additional time and or materials possible. Please advise. Thank you! Document ID: B5EE778A8DC7DA9C4FFFD479A848DEAA Engineering Firm RESPONSE ANSWERED: Harried Marian DATE RECEIVED: DATE ANSWERED: TITLE: Sr. PM O 12/8/2025 12/8/2025 _Engineering Firm RESPONSE TO CONTRACTOR: I.C.E. _ To re-establish the required pavement support section, proceed as follows: 1. Excavation of Unsuitable Materials; Excavate all unsuitable subbase and underlying muck to a depth of 2.75 feet below the proposed finished grade to remove all unstable, pumping material. 2. Placement of Replacement P-219 Material (Subbase Replacement); Backfill the excavation with P-219 crushed aggregate base material placed in two (2) compacted lifts of 12 inches each. Each lift shall be moisture -conditioned, compacted, and proofrolled in accordance with the specifications. Field density acceptance is required on each lift to achieve in place dry density at least 100% of the standard proctor ASTM D698) max, dry density. 3. Placement of Final 6-Inch Base Layer: After acceptance of the two 12-inch lifts, place the final 6-inch P-219 base course per project plans and specifications. Compact and test to meet all specified requirements. 4. Measurement of Repair Area; The RPR will measure and quantify the limits of excavation and replacement for documentation and payment purposes. 5. Time Considerations; As the unsuitable subbase prevented proofrolling and halted construction activities, the Contractor may request additional contract time as needed, in accordance with the procedures outlined in the contract documents. Any requested time extension shall include supporting justification and requires uwne(o appivvJ. CONTRACTING OFFICER'S SIGNATURE I ��f" i r/ v Document ID: B5EE778A8DC7DA9C4FFFD479A848DEAA I CadE" r—urn...,oa,mmUnm*"Subb 9VatwxRopbml.eRF9otDaO) I = a""! O' B9B8 OMSe(6.6'li9s fe166C jy 266 W 519.99 fa6W.o61 L� J Document ID: BSEE778A8DC7DA9C4FFFD479A848DEAA crry or SQ3ASTIAN 14 HOME OF PELICAN ISLAND Exhibit B City of Sebastian Holiday Schedule Procurement Division 1225 Main Street, Sebastian, FL 32958 Phone: 772-388-8231 Page 4 of 7 Document ID: B5EE778A8DC7DA9C4FFFD479A848DEAA CITY OF Sf]F;ASTjAN HOME OF PELICAN ISLAND City of Sebastian Holiday Schedule (November 2025, December 2025 and January 2026) Date Tuesday, November 11, 2025 Thursday, November 27, 2025 Friday, November 28, 2025 Wednesday, December 24, 2025 Thursday, December 25, 2025 Thursday, January 1, 2026 Monday, January 19, 2026 Procurement Division Holiday Veteran's Day Thanksgiving Day Friday after Thanksgiving Day before Christmas Day Christmas Day New Year's Day Martin Luther King, Jr. 1225 Main Street, Sebastian, FL 32958 Phone:772-388-8231 Page 5 of 7 Document ID: B5EE778A8DC7DA9C4FFFD479A848DEAA Cll % Oi SF13ASTI,NN HOME OF PELICAN ISLAND Exhibit C Revised Liquidated Damages Schedule Procurement Division 1225 Main Street, Sebastian, FL 32958 Phone: 772-388-8231 Page 6 of 7 Document ID: B5EE778A8DC7DA9C4FFFD479A848DEAA CITY OF Sfj3ASTI)kN HOME OF PELICAN ISLAND 16.2 Liquidated Damages: Completion of Phases 1 & 2 80 $500 PER DAY Phases 1 & 2 SHALL be completed by January 15, 2026 Punch list and permanent markings $500 PER DAY Punch list/permanent markings SHALL be completed by February 15, 2026 1 Procurement Division 1225 Main Street, Sebastian, FL 32958 Phone: 772-388-8231 Page 7 of 7 Document ID: B5EE778A8DC7DA9C4FFFD479A848DEAA