Loading...
HomeMy WebLinkAboutMancil's Tractor Service, Inc. Airport Dr. East ImprovementsanOf SEm.AT" HOME OF PELICAN ISLAND 1225 Main Street Sebastian, FL 32958 (772)388-8215 Phone July 3, 2017 Mancil's Tractor Service, Inc. 8530 SW Jayme Way Palm City, FL 34990 RE: Release of Payment & Performance Bonds for Sebastian Municipal Airport — Airport Storage Building—Bond # 0664487. To Whom It May Concern: I am releasing payment and performance bonds #0664487 issued by International Fidelity Insurance Company in the amount of $507,986.53 to the Sebastian Airport for Airport Storage Building. Sincerely, W(lEdll,p aneJJ Williams, MMC City Clerk Attachment: Original Bonds #0664487 cnnCr SEAT" HOME OF PELICAN ISLAND 1225 Main Street Sebastian,FL 32958 (772)388-8215 Phone June 26, 2017 Mancil's Tractor Service, Inc. 4551 SE Hampton Court Stuart, FL 34997 RE: Release of Payment & Performance Bonds for Sebastian Municipal Airport — Airport Drive East Improvements—Bond # K08896422 To Whom It May Concern: I am releasing payment and performance bonds #K08896422 issued by Westchester Fire Insurance Company in the amount of $752,741.00 to the Sebastian Airport for Airport Drive East Improvements. Sincerely, J nette Williams, MMC City Clerk Attachment: Original Bonds #K08896422 PUBLIC WORKS BOND THIS IS THE FRONT PAGE OF THIS PERFORMANCE AND PAYMENT BOND ISSUED IN COMPLIANCE WITH CHAPTER s255.05 FLORIDA STATUTES. BOND NO. xO8896422 CONTRACTOR NAME: Mancil' s Tractor Service, In CONTRACTOR ADDRESS: 4551 SE Hampton Court Stuart, FL 34997 CONTRACTOR PHONE NO. (772-288-0951 SURETY COMPANY: Wa s t- r_ h P g t- P r Firp T n- i r i n cP C Street-WA10H 436 Walnut Philadelphia, PA 19106 (21 5 OWNERNAME: City of Sebastian OWNER ADDRESS: 1 225 Main Street Sebastian, FL 32958 OWNER PHONE NO. ( ) OBLIGEE NAME:(If contracting entity is different from the owner, the contracting public entity) OBLIGEE ADDRESS: OBLIGEE PHONE NO. ) BOND AMOUNT: $752p741-00 CONTRACT NO. (If Applicable) DESCRIPTION OF WORK: Sebastain Municipal Airport -Airport Drive East Improvements PROJECT LOCATION: S eba s t a i n, FL LEGAL DESCRIPTION: FRONT PAGE (ALL OTHER BOND PAGES ARE DEEMED SUBSEQUENT TO THIS PAGE REGARDLESS OF ANY PAGE NUMBERS THAT MAY BE PRE-PRINTED THEREON) PERFORMANCE BOND Bond No.: Koum22 CONTRACTOR: (Name, legal status and address) Mancirs Tractor Servlce, Inc. 4551 SE Hampton Court Stuart, FL 34997 OWNER: (Name, legal status and address) City of Sebastian 1225 Main Street Westchester Fine Insurance Company SURETY: (Name, legal status and principal place of business) Westchester Fire Insurance Company 436 Walnut Street WA10H Philadelphia, PA 19106 Sebastian, FL 32958 CONSTRUCTION CONTRACT Date: Amount: Seven Hundred My Two Thousand Seven Hundred Forty One Dollars Description: (Name and location) Sebastain Munkpal Airport -Airport Drive East Improvemeets stain, FL BOND Date: February 10, 2014 (Not earlier than Construction Contract Date) Amount Seven Hundred Fifty Two Thousand Forty0neDollars Modifications to this Bond: X See Section 16 CONTRACTOR AS PRINCIPAL �'; V� �� _ URETY Company: Mancil's Tracto n�� 1 n estcheste L Name and Title: Don R. Afancil Jr. Presto%Itpqgi�ePerfonnance • • . , , , , ame and Title: Robert Barra Attorney In Fact (Arty additional signatures appear on the Bond) (FOR INFORMATION ONLY— Name, address and telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE: Bob Barra Bonds, Inc. (Architect, Engineer or other party.) 9373 West Sample Road, Ste 206 Coral Springs, FL 33065 (Corporate Seal) § 1 The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner for the performance of the Construction Contract, which is incorporated herein by reference. § 2 If the Contractor performs the Construction Contract, the Surety and the Contractor shall have no obligation under this Bond, except when applicable to participate in a conference as provided in Section 3. § 3 If there is no Owner Default under the Construction Contract, the Surety's obligation under this Bond shall arise atter .1 the Owner first provides notice to the Contractor and the Surety that the Owner is considering declaring a Contractor Default Such notice shall indicate whether the Owner is requesting a conference among the Owner, Contractor and Surety to discuss the Contractor's performance. If the Owner does not request a conference, the Surety may, within five (5) business days after receipt of the Owner's notice, request such a conference. If the Surety timely requests a conference, the Owner shall attend. Unless the Owner agrees otherwise, any conference requested under this Section 3.1 shall be held within ten (10) business days of the Surety's receipt of the The Company executing this bond vouches that this document conforms to American Institute of Architects Document A312,2010 edition 1 Owner's notice. If the Owner, the Contractor and the Surety agree, the Contractor shall be allowed a reasonable time to perform the Construction Contract, but such an agreement shall not waive the Owner's right, if any, subsequently to declare a Contractor Default; 2 the Owner declares a Contractor Default, terminates the Construction Contract and notifies the Surety; and .3 the Owner has agreed to pay the Balance of the Contract Price in accordance with the terms of the Construction Contract to the Surety or to a contractor selected to perform the Construction Contract. § 4 Failure on the part of the Owner to comply with the notice requirement in Section 3.1 shall not constitute a failure to comply with a condition precedent to the Surety's obligations, or release the Surety from its obligations, except to the extent the Surety demonstrates actual prejudice. § 5 When the Owner has satisfied the conditions of Section 3, the Surety X11 promptly and at the Surety's expense take one of the following actions: § 5.1 Arrange for the Contractor, with the consent of the Owner, to perform and complete the Construction Contract; § 52 Undertake to perform and complete the Construction Contract itself, through its agents or independent contractors; § 5.3 Obtain bids or negotiated proposals from qualified contractors acceptable to the Owner for a contract for performance and completion of the Construction Contract, arrange for a contract to be prepared for execution by the Owner and a contractor selected with the Owner's concurrence, to be secured with performance and payment bonds executed by a qualified surety equivalent to the bonds issued on the Construction Contract, and pay to the Owner the amount of damages as described in Section 7 in excess of the Balance of the Contract Price incurred by the Owner as a result of the Contractor Default; or § 5.4 Waive its right to perform and complete, arrange for completion, or obtain a new contractor and with reasonable promptness under the circumstances: .1 After investigation, detennine the amount for which it may be liable to the Owner and, as soon as practicable after the amount is determined, make payment to the Owner, or 2 Deny liability in whole or in part and notify the Owner, citing the reasons for denial. § 6 If the Surety does not proceed as provided in Section 5 with reasonable promptness, the Surety shall be deemed to be in default on this Bond seven days after receipt of an additional written notice from the Owner to the Surety demanding that the Surety perform its obligations under this Bond, and the Owner shall be entitled to enforce any remedy available to the Owner. If the Surety proceeds as provided in Section 5.4, and the Owner refuses the payment or the Surety has denied liability, in whole or in part, without fiuther notice the Owner shall be entitled to enfarre any remedy available to the Owner. § 7 If the Surety elects to act under Section 5.1, 5.2 or 5.3, then the responsibilities of the Surety to the Owner shall not be greater than those of the Contractor under the Construction Contract, and the responsibilities of the Owner to the Surety shall not be greater than those of the Owner under the Construction Contract. Subject to the commitment by the Owner to pay the Balance of the Contract Price, the Surety is obligated, without duplication, for .1 the responsibilities of the Contractor for correction of defective work and completion of the Construction Contract; 2 additional legal, design professional and delay costs resulting from the Contractor's Default, and resulting from the actions or failure to act of the Surety under Section 5; and .3 liquidated damages, or if no liquidated damages are specified in the Construction Contract, actual damages caused by delayed performance or non-performance of the Contractor. § 8 If the Surety elects to act under Section 5.1, 53 or 5.4, the Surety's liability is limited to the amount of this Bond. § 9 The Surety shall not be liable to the Owner or others for obligations of the Contractor that are unrelated to the Construction Contract, and the Balance of the Contract Price shall not be reduced or set off on account of any such unrelated obligations. No right of action shall accrue on this Bond to any person or entity other than the Owner or its heirs, executors, administrators, successors and assigns. § 10 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. § 11 Any proceeding, legal or equitable, under this Bond may be instituted in any court of competent jurisdiction in the location in which the work or part of the work is located and shall be instituted within two years after a declaration of Contractor Default or within two years after the Contractor ceased working or within two years after the Surety refuses or fails The Company executing this bond vouches that this document conforms to American Institute of Architects Document A312,2010 edition 2 to perform its obligations under this Bond, whichever occurs first. If the provisions of this Paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. § 12 Notice to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. § 13 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished, the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. § 14 Defin"dions § 14.1 Balance of the Contract Price. The total amount payable by the Owner to the Contractor under the Construction Contract after all proper adjustments have been made, including allowance to the Contractor of any amounts received or to be received by the Owner in settlement of insurance or other claims for damages to which the Contractor is entitled, reduced by all valid and proper payments made to or on behalf of the Contractor under the Construction Contract. § 14.2 Construction Contract. The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and changes made to the agreement and the Contract Documents. § 14.3 Contractor Default. Failure of the Contractor, which has not been remedied or waived, to perform or otherwise to comply with a material term of the Construction Contract. § 14.4 Owner Default. Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. § 14.5 Contract Documents. All the documents that comprise the agreement between the Owner and Contractor. § 15 If this Bond is issued for an agreement between a Contractor and subcontractor, the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. § 16 Modifications to this bond are as follows: NIA NO QUB" (Space is provided below for additional signatures of added parties, other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) Signature: Name and Title: Address: Signature: Name and Title: Address: The Company executing this bond vouches that this document conforms to American Institute of Architects Document A3129 2010 edition 3 PAYMENT BOND Bond No.: K08896422 Westchester Fire Insurance Company CONTRACTOR: - SURETY: (Name, legal status and address) (Name, legal status and principal place of business) Mancil's Tractor Service, Inc. Westchester Fire Insurance Company 4551 SE Hampton Court 436 Walnut Street WA10H Stuart, FL 34997 Philadelphia, PA 19106 OWNER:- WNER:(Name, (Name,legal status and address) City of Sebastian 1225 Main Street Sebastian, FL 32958 CONsnwcnoN CONTRACT Date: Amount: Seven Hundred Fifty Two Thousand Seven Hundred Forty One Dollars Description: (Name and location) Sebastian Municipal Ah -port -Airport Drive East Improvements Sebastian, FL BOND Date: February 10, 2014 (Not earlier than Construction Contract Date) Amount: Seven Hundred Fifty Two Thousand Seven Hundred Forty One Dollars Modifications to this Bond: X See Section 18 CONTRACTOR AS PRINCIPALC ; •• P� •••.• ;, URETY Company: �t~rate" `�}, • mpany: (Corporate Seal) Mandi's TractoQ : �L any Name and 'ride: Don R rMancil Jr. 1904 • • e and 1"ttle: Robert Barra Attorney in Fact (Arty additional signatures appear onpr,o�' aymerrt Bond) (FOR INFORMATION ONLY— Name, address and telephone) AGENT or BROKER: OWNER`S REPRESENTATIVE: Bob Barra Bonds, Inc. (Architects Engineer or other party.) 9373 West Sample Road, Ste 206 Coral Springs, FL 33065 § 1 The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner to pay for labor, materials and equipment furnished for use in the performance of the Construction Contract, which is incorporated herein by reference, subject to the following terms. § 2 If the Contractor promptly makes payment of all sums due to Claimants, and defends, indemnifies and holds harmless the Owner from claims, demands, liens or suits by any person or entity seeking payment for labor, materials or equipment The Company execu in8 this bond vouches that this document conforms to Amain lnSUtute of Architects Document A312,2010 emon 1 furnished for use in the performance of the Construction Contract, then the Surety and the Contractor shall have no obligation under this Bond. § 3 If there is no Owner Default under the Construction Contract, the Surety's obligation to the Owner under this Bond shall arise after the Owner has promptly notified the Contractor and the Surety (at the address described in Section 13) of claims, demands, liens or suits against the Owner or the Owner's property by any person or entity seeking payment for labor, materials or equipment furnished for use in the performance of the Construction Contract and tendered defense of such claims, demands, liens or suits to the Contractor and the Surety. § 4 When the Owner has satisfied the conditions in Section 3, the Surety shall promptly and at the Surety's expense defend, indemnify and hold harmless the Owner against a duly tendered claim, demand, lien or suit. § 5 The Surety's obligations to a Claimant under this Bond shall arise after the following. § 5.1 Claimants, who do not have a direct contract with the Contractor, .1 have furnished a written notice of non-payment to the Contractor, stating with substantial accuracy the amount claimed and the name of the party to whom the materials were, or equipment was, furnished or supplied or for whom the labor was done or performed, within ninety (90) days after having last performed labor or last furnished materials or equipment included in the Claim; and 2 have sent a Claim to the Surety (at the address described in Section 13). § 5.2 Claimants, who are employed by or have a direct contract with the Contractor, have sent a Claim to the Surety (at the address described in Section 13). § 6 If a notice of non-payment required by Section 5. 1.1 is given by the Owner to the Contractor, that is sufficient to satisfy a Claimant's obligation to furnish a written notice of non-payment under Section 5.1.1. § 7 When a Claimant has satisfied the conditions of Sections 5.1 or 5.2, whichever is applicable, the Surety shall promptly and at the Surety's expense take the following actions: § 7.1 Send an answer to the Claimant, with a copy to the Owner, within sixty (60) days after receipt of the Cl" stating the amounts that are undisputed and the basis for challenging any amounts that are disputed; and § 72 Pay or arrange for payment of any undisputed amounts. § 7.3 The Surety's failure to discharge its obligations under Section 7.1 or Section 7.2 shall not be deemed to constitute a waiver of defenses the Surety or Contractor may have or acquire as to a Claim, except as to undisputed amounts for which the Surety and Claimant have reached agreement. If, however, the Surety fails to discharge its obligations under Section 7.1 or Section 7.2, the Surety shall indemnify the Claimant for the reasonable attorney's fees the Claimant incurs thereafter to recover any sums found to be due and owing to the Claimant. § 8 The Surety's total obligation shall not exceed the amount of this Bond, plus the amount of reasonable attorney's fees provided under Section 73, and the amount of this Bond shall be credited for any payments made in good faith by the Surety. § 9 Amounts owed by the Owner to the Contractor under the Construction Contract shall be used for the performance of the Construction Contract and to satisfy claims, if any, under any construction performance bond. By the Contractor furnishing and the Owner accepting this Bond, they agree that all funds earned by the Contractor in the performance of the Construction Contract are dedicated to satisfy obligations of the Contractor and Surety under this Bond, subject to the Owner's priority to use the funds for the completion of the work. § 10 The Surety shall not be liable to the Owner, Claimants or others for obligations of the Contractor that are unrelated -to the Construction Contract The Owner shall not be liable for the payment of any costs or expenses of any Claimant under this Bond, and shall have under this Bond no obligation to make payments to, or give notice on behalf of, Claimants or otherwise have any obligations to Claimants under this Bond § 11 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. The Company meadhV this bond wtrches that this dmuneat conform to American InsMute of An:hftects Document A312,2010 edition § 12 No suit or action shall be commenced by a Claimant under this Bond other than in a court of competent jurisdiction in the state in which the project that is the subject of the Construction Contract is located or ager the expiration of one year from the date (1) on which the Claimant sent a Claim to the Surety pursuant to Section 5.1.2 or 5.2, or (2) on which the last labor or service was performed by anyone or the last materials or equipment were famished by anyone under the Construction Contract, whichever of (1) or (2) first occurs. If the provisions of this Paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction ofthe suit shall be applicable. § 13 Notice and Claims to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. Actual receipt of notice or Claims, however accomplished, shall be sufficient compliance as of the date received. - § 14 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so famished, the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. § 15 Upon request by any person or entity appearing to be a potential beneficiary of this Bond, the Contractor and Owner shall Prosy furnish a copy of this Bond or shall permit a copy to be made. § 16 Definitions § 16.1 Claim. A written statement by the Claimant including at a minimum: .1 the name of the Claimant; 2 the name of the person for whom the labor was done, or materials or equipment famished; .3 a copy of the agreement or purchase order pursuant to which labor, materials or equipment was furnished for use in the performance of the Construction Contract; A a brief description of the labor, materials or equipment furnished; .5 the date on which the Claimant last performed labor or last furnished materials or equipment for use in the perforncance of the Construction Contract; .6 the total amount earned by the Claimant for labor, materials or equipment furnished as of the date of the Claim; .7 the total amount of previous payments received by the Claimant; and .8 the total amount due and unpaid to the Claimant for labor, materials or equipment furnished as of the date of the Claim. § 162 Claimant. An individual or entity having a direct contract with the Contractor or with a subcontractor of the Contractor to firmish labor, materials or equipment for use in the performance of the Construction Contract. The term Claimant also includes any individual or entity that has rightfully asserted a claim under an applicable mechanic's Gen or similar statute against the real property upon which the Project is looted. The intent of this Bond shall be to include without limitation in the terms "labor, materials or equipment" that part of'water, gas, power, light, heat, oil, gasoline, telephone service or rental equipment used in the Construction Contract, architectural and engineering services required for performance of the work of the Contractor and the Contractor's subcontractors, and alt other items for which a mechanic's Gen may be asserted in the jurisdiction where the labor, materials or equipment were furnished. § 16.3 Construction Contract. The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and all changes made to the agreement and the Contract Documents. § 16.4 Owner Default. Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. § 16.5 Corttract Doc m ents. All the documents that comprise the agreement between the Owner and Contractor. § 17 If this Bond is issued for an agreement between a Contractor and subcontractor, the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. The Company executing this bond vouches that this document conforms to American institute of AmbRects Document A31Z 2010 edition 3 § 118 Modifications to this bond are as follows: MA NO SIGNATURE REQUIRED (Space is provided below for additional signatures of added parties, other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) Signature: Name and Title.- Address: itle:Address: Signature: Name and Title: Address: The Company awcuting this bond vouches that this document conforms to Aman Institute of Architects Document A312, 2010 4 edition 0 THE BACK OF THIS DOCUMENT LISTS VARIOUS SECURITY FEATURES ■ THAT WILL PROTECT AGAINST COPY COUNTERFEIT AND ALTERATION. 0 Please look for -the following additional security features-befdre accepting this document. IF NOT PRESENT, DO NOT NEGOTIATE THE DOCUMENT. • Laid lines on the back of document should be in alignment or the document is not authentic - watch for cut and paste. • Micraprinting - under magnification, the inside border on the front of this document should read: "Standard Register Standardized Security". • Thermochromic Ink - Standard Register mark on back of document fades from blue to clear when heat is applied. • An Artificial Watermark is present and is viewable at an angle. • Security void pattern on front if copied. i 007169074"