Loading...
HomeMy WebLinkAboutAtlantic Roofing of Vero Beach, IncCRY OF SEB`ST" HOME OF PELICAN ISLAND 1225 Main Street Sebastian, FL 32958 (772)388-8214 Phone January 30, 2017 Atlantic Roofing II of Vero Beach, Inc. 4020 43rd Avenue Vero Beach GL 32960 RE: Release of Payment & Performance Bond for the Sebastian Police Department Re -Roofing Project in the amount of $70,595.00 -- Bond # 6021078723. Dear Atlantic Roofing II: I am releasing payment and performance bonds #6021078723 issued by United States Fire Insurance Company in the amount of $70,595.00 to the City of Sebastian to "Provide Sebastian Police Station Re -Roofing. Sincerely, Jnetta Williams, MMC City Clerk Attachment, Original Bonds #6021078723 cc: City Manager City Attorney City Engineer Cathy Testa From: Randy Moyer Sent: Friday, January 27, 2017 1:42 PM To: Cathy Testa Subject: RE: Certificate of project completion Hi Cathy. Please release the Performance Bond Thanks Have a safe day. Randy From: Cathy Testa Sent: Friday, January 27, 2017 11:58 AM To: Randy Moyer Subject: RE: Certificate of project completion Ok... that would be great O From: Randy Moyer Sent: Friday, January 27, 2017 11:57 AM To: Frank Watanabe; Cathy Testa Subject: FW: Certificate of project completion Hi Cathy. Let me just double check with Frank. I do not have any reason to hold it. Thanks Have a safe day. Randy From: Cathy Testa Sent: Friday, January 27, 2017 8:55 AM To: Randy Moyer Subject: Certificate of project completion Hi Randy, I received a Certificate of Completion for the Police Roof Repairs. Can I release the bond back to Atlantic Roofing? FRONT PAGE OF PUBLIC PAYMENT BOND Florida Statute 255.05 Attached to and part of BOND NO. 6021078723 In Compliance with Florida Statutes Chapter 255.05 (1) (a), Public Work. All other Bond page(s) are deemed subsequent to this page regardless of any number (s) that may be pre-printed thereon. CONTRACTOR: Atlantic Roofing II of Vero Beach, Inc. 4020 43rd Avenue Vero Beach, FL 32960 (772) 492-8493 SURETY: United States Fire Insurance Company 305 Madison Avenue Morristown, NJ 07960 973-490-6600 AGENT: Nielson, Rosenhaus & Associates 8401 Lake Worth Road, Ste. 2-231 Lake Worth, FL 33467 561-713-1453 OBLIGEE: City of Sebastian 1225 Main Street Sebastian, FL 32958 772-589-5330 PROJECT: Sebastian Police Station Reroof Bond No. 6021078723 Document A312TM — 2010 Conforms with The American Institute of Architects AIA Document 312 Performance Bond CONTRACTOR: (Nmne, legal status and address) Atlantic Roofing II of Vero Beach, Inc. 4020 43RD Avenue Vero Beach FL 32960 OWNER: (Mime, legal stains acrd address) City of Sebastian 1225 Main Street Sebastian FL 32958 CONSTRUCTION CONTRACT Date: June 16, 2016 Amount: $ 70,595.00 SURETY: (Name, legal status and princlpal place of brulness) United States Fire Insurance Company 305 Madison Avenue Morristown NJ 07960 Mailing Address for Notices 305 Madison Avenue Morristown NJ 07960 This document has Important legal consequences. Consultation with an attorney Is encouraged with respect to its completion or modlncanon. Any singular reference to Contractor, Surely, Owner or other party shall be considered plural where applicable. Seventy Thousand Five Hundred Ninety Five Dollars and 001100 Description: (Name and location) Sebastian Police Station Reroof Located at 1225 Main Street Sebastian FL 32958 BOND Date: July 7, 2016 (No(earlier than Construction Contract Date) Amount: $ 70,595,00 Seventy Thousand Five Hundred Ninety Five Dollars and 001100 Moditicadons to this Bond: © None F1 See Section 16 CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) Atlantic Roofing II of Vero Be In United States Fire Insurance Company / 5lgnanl(C� Signature: Name Name Kevin R. Wojtowicz end Titta. A and Title: Attorney -in -Fact & FL Licensed Agent (Any additional signatures appear on the last page ofthis Perfonnonee Bond.) (FOR LYFO&ILITlON ONLY —Name, address and telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE: Nielson, Rosenhaus&Associates (Architect, Engineer or otherparry:) 8401 Lake Worth Road, Ste. 2-231 N/A Lake Worth FL 33467 561-713-1453 N/A 8-1852/AS 8/10 § 1 The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner for the performance of the Construction Contract, which is incorporated herein by reference. § 2 If the Contractor performs the Construction Contract, the Surety and the Contractor shall have no obligation under this Bond, except when applicable to participate in a conference as provided In Section 3. § 3 If there is no OwnerDefault under the Construction Contract, the Surety's obligation under this Bond shall arise ager .1 the Owner first provides notice to the Contractor and the Surety that the Owner is consldering declaring a Contractor Default. Such notice shall indicate whether the Owner is requesting a conference among the Owner, Contractor and Surety to discuss the Contractor's performance. If the Owner docs not request a conference, the Surety may, within five (S) business days after receipt of the Owner's notice, request such a conference. If the Surety timely requests a conference, the Owner shall attend. Unless the Owner agrees otherwise, any conference requested under this Section 3.1 shall be held within ton (10) business days of the Surety's receipt of the Ownees notice. If the Owner, the Contractor and the Surety agree, the Contractor shall be allowed a reasonable time to perform the Construction Contract, but such an agreement shall not waive the Owner's right, if any, subsequently to declare a Contractor Default; .2 the Owner declares a Contractor Default, terminates the Construction Contract and notifies the Surety; and .3 the Owner has agreed to pay the Balance of the Contract Price in accordance with the terns of the Construction Contract to the Surety or to a contractor selected to perform the Construction Contract. ' § 4 Failure on the part of the Owner to comply with the notice requirement in Section 3.1 shall not constitute a failure to comply with a condition precedent to the Surety's obligations, or release the Surety from its obligations, except to the extent the Surety demonstrates actual prejudice. § 6 When the Owner has satisfied the conditions of Section 3, the Surety shall promptly and at the Surety's expense talm one of the following actions: § 5.1 Arrange for the Contractor, with the consent of the Owner, to perform and complete the Construction Contract; § 6.2 Undertake to perform and complete the Construction Contract itself; through Its agents or Independent contractors; § 6.3 Obtain bids or negotiated proposals from qualified contractors acceptable to the Owner for a contract for performance and completion of the Construction Contract, arrange for a contract to be prepared for oxecution by the Owner and a contractor selected with the Owner's concurrence, to be secured with performance and payment bonds executed by a qualified surety equivalent to the bonds issued on the Construction Contract, and pay to the Owner the amount of damages as described in Section 7 In excess of the Balance of the Contract Price incurred by the Owner as a result of the Contractor Default; or § S.4 Waive its tight to perform and complete, arrange for completion, or obtain a new contractor and with reasonable promptness under the circumstances: After investigation, determine the amount for which it may be liable to the Owner and, as soon as practicable after the amount Is determined, make payment to the Owner, or Deny liability in whole or In part and notify the Owner, citing the reasons for denial. § 6 If the Surety does not proceed as provided in Section S with reasonable promphu&% the Surety shall be deemed to be in default on this Bond seven days atter receipt of an additional written notice fium the Owner to the Surety demanding that the Surety perform Its obligations under this Bond, and the Owner shall be entitled to enforce any remedy available to the Owner. If the Surety proceeds as provided In Section SA, and the Owner refiuses the payment or the Surety has denied liability, In whole or in part, without further notice the Owner shall be entitled to enforce any remedy available to the Owner. S-186VAS 8H0 § 7 If the Surety elects to act under Section 5.1, 5.2 or 5.3, then the responsibilities of the Surety to the Owner shall not be greater than those of the Contractor under the Construction Contract, and the responsibilities of the Owner to the Surety shall not be greater than those of the Owner under the Construction Contract. Subject to the commitment by the Owner to pay the Balance of the Contract Price, the Surety is obligated, without duplication, for .1 the responsibilities of the Contractor for correction of defective work and completion of the. Construction tion Contract; .2 additional legal, design professional and delay casts resulting from The Contractor's Default, and resulting from the actions or failure to act of the Surety under Section 5; and .3 liquidated damages, or If no liquidated damages are specified in the Construction Contract, actual damages caused by delayed performance or non-performance of the Contractor. § 8 If the Surety elects to act under Section 5.1, 5.3 or 5.4, the Surety's liability is limited to the amount of this Bond. § 9 The Surety shall not be liable to the Owner or others for obligations of the Contractor that aro unrelated to the Construction Contract, and the Balance of the Contract Price shall not be reduced or set off on account of any such unrelated obligations. No right of action shall accrue on this Bond to any person or entity other than the Owner or its heirs, executors, administrators, successors and assigns. § 10 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. § 11 Any proceeding, legal or equitable, under this Bond may be instituted in any court of competent jurisdiction in the location in which the work or part of the work is located and shall be instituted within two years after a declaration of Contractor Default or within two years after the Contractor ccascd working or within two years after the Surety refuses or fails to perform its obligations under this Bond, whichever occurs first. If the provisions of this Paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. § 12 Notice to the Surety, Oho Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. § 13 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so lirmished, the intent is that this Bond shall be construed as a statutory bond and not as a common lawhond. § 14 Definitlons § 14.1 Balance of the Contract Price. The total amount payable by the Owner to the Contractor under the Construction Contract after all proper adjustments have been made, including allowance to the Contractor of any amounts received or to be received by the Owner in settlement of Insurance or other claims for damages to which the Contractor is entitled, reduced by all valid and proper payments made to or on behalfof the Contractor under the Construction Contract. § 14.2 Construction Contract. the agreement between the Owner and Contractor Identified on the cover page, including all Contract Documents and changes made to the agreement and the Contract Documents. § 14.3 Contractor Default railure of the Contractor, which has not been remedied or waived, to perform or other Ase to comply with a material tern of the Construction Contract. § 14.4 Owner Default. Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terns of the Construction Contract. § 14.6 Contract Documents. All the documents that comprise the agreement between the Owner and Contractor. § 15 If this Bond is issued for an agreement between a Contractor and subcontractor, the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. S-1862/AS 8110 § 18 Modifications to this bond are as rollows: (Space Is provided below for additional signatures afadded parties, other than those appearing on the cover page) CONTRACTOR AS PRINCIPAL SURETY Company: ,1 (Corporate Seal) Company: (Corporate Seal) Sigonm`re: - ,,R Nome and Title: )/A�/t�� Address S-185VAS 8110 Signature: Nome and Title: Address THE PROVISIONS AND LIMITATIONS OF SECTION 255.05 FLORIDA STATUTES, INCLUDING BUT NOT LIMITED TO THE NOTICE AND TIME LIMITATIONS IN SECTIONS 255.05(2) AND 255.05(10), ARE INCORPORATED IN THIS BOND BY REFERENCE. Bond No. 6021076723 Document A312 TM —2010 Conforms with The American Institute of Architects AIA Document 312 Payment Bond CONTRACTOR: (Marne, legal status and address) Atlantic Roofing II of Vero Beach, Inc. 4020 43RD Avenue Vere Beach FL 32960 OWNER: (Name, legal status and address) City of Sebastian 1225 Main Street Sebastian FL 32958 CONSTRUCTION CONTRACT Date: June 16, 2016 Amount: S 70,595.00 SURETY: (Norte, legal status and principal place of business) United States Fire Insurance Company 305 Madison Avenue Morristown NJ 07960 Mailing Address for Notices 305 Madison Avenue Morristown NJ 07960 This document has Important legal consequences. Consultation with an attorney Is encouraged with respect to its completion or modification. Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable. SeventyThousand Five Hundred Ninety Five Dollars and 00/100 Description: Name and location) Sebastian Police Station Reroof Located at 1225 Main Street Sebastian FL 32958 BOND Date: July 7, 2016 Not earlier than Construction Contract Date) Amount: 570,595.00 Seventy Thousand Five Hundred Ninety Five Dollars and 00/100 Modifications to this Bond: 0 None Q See Section l8 CONTRACTOR AS PRINCIPAL Company: (Corporate Seal) Atlantic Roofing If of Vero WBeln Signrturc: Na ac ��/�C� //�Jh l /%f �✓ and T_::(e: /� � i�'Q•c,.`f/�/Fjr' SURETY Company: (Corporate Seal) United States Fire Insurance Company Signature: It -i- �--> Name Kevin R. Wojtowicz and Title: Attorney -in -Fact & FL Licensed Agent (Arty additional signatures appear on Nie last page of this Parnent Bond.) (FOR INFORWATIONONLY—Noone, address and telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE: Nielson, Rosenhaus &Associates (Architect, Engineer ororherparty.) 8401 Lake Worth Road, Ste. 2-231 NIA Lake Worth FL 33467 561-713-1453 N/A S-2119/AS 8110 § 1 The Contractor and Surety, Jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner to pay for labor, materials and equipment furnished for use in the performance of the Construction Contract, which is incorporated herein by reference, subject to the following terms. § 2 if the Contractor promptly makes payment of all sums due to Claimants, and defends, indemnifies and holds harmless the Owner from claims, demands, liens or suits by any person or entity seeking payment fbr labor, materials or equipment furnished for use in the performance of the Construction Contract, then the Surety and the Contractor shall have no obligation under this Band. § 3 inhere is no Owner Default under the Construction Contract, the Surety's obligation to the Owner under this Bond shall arise after the Owner has promptly notMed. the Contractor and the Surety (at the address described in Section 13) of claims, demands, liens or suits against the Owner or the Owner's property by any person or entity seeking payment for labor, materials or equipment furnished for use in the performance of the Construction Contract and tendered defense of such claims, demands, liens or suits to the Contractor and the Surety. § 4 When the Owner has satisfied the conditions in Section 3, the Surety shall promptly and at the Surety's expense defend, Indemnify and hold harmless the Owner against a duly tendered clalm, demand, lien or suit. § 5 The Surety's obligations to a Claimant under this Bond shall arise after the following: § 6.1 Claimants, who do not have a direct contract with the Contractor, .1 have famished a written notice of nen-payment to the Contractor, stating with substantial accuracy tho amount claimed and the name of the party to whom the materials were, or equipment was, furnished or supplied or for whom the labor was done or performed, within ninety (90) days after having last performed labor or last furnished materials or equipment included In the Claim; and .2 have sent a Claim to the Surety (at the address described In Section I3). § 5.2 Claimants, who aro employed by or have a direct contract with the Contractor, have sent a Claim to the Surety (at the address described in Section 13). § 0 If a notice of non-payment required by Section 5.1.1 Is given by the Owner to the Contractor, that is sufficient to satisfy a Claimant's obligation to fiunish a written notice of non-payment under Section 5.1.1. § T When a Claimant has satisfied the conditions of Sections 5.1 or 5.2, whichever is applicable, the Surety shall promptly and ut the Surety's expense take the following actions: § 7.1 Send an answer to the Claimant, with a copy to the Owner, within sixty (60) days after receipt of the Claim, stating the amounts that are undisputed and the basis for challenging any amounts that arc disputed; and § 7.2 Pay or wage for payment of any undisputed amounts. § 7.3 The Surety's (ailuro to discharge its obligations under Section 7.1 or Section 7.2 shall not be dccmed to constitute a waiver of defenses the Surety or Contractor may have or acquire as to a Claim, except as to undisputed amounts for which the Surety and Claimant have reached agreement If, however, the Surety falls to discharge its obligations under Section 7.1 or Section 7.Z, the Surety shall indemnify the Claimant for the reasonable attorney's fees the Claimant incurs thereafter to recover any sums found to be due and owing to the Clalmemt. § q The Surety's total obligation shall not exceed the amount of this Bond, plus the amount of reasonable attomey's fees provided under Section 73, and the amount of this Bond shall be credited for any payments made in good fhith by the Surety. § 9 Amounts owed by the Owner to the Contractor under the Construction Contract shall be used for the performance of the Construction Contract and to satisfy claims, If any, under any construction performance bond. By the Contractor fi,rnlshing and the Owner accepting this Bond, they agree that all fiends eamed by the Contractor in the performance of the Construction Contract are dedicated to satisfy obligations of the Contractor and Surety under this Bond, subject to the Owner's priority to use the ftmds for the completion of the work. . S-21401AS 8110 § 10 The Surety shalt not be liable to the Owner, Claimants or others for obligations of the Conhmctor that arc unrelated to the Construction Contract. The Owner shall not be liable for the payment of any costs or expenses of any Claimant under this Bond, and shall have under this Bond no obligation to matte payments to, or give notice on behalf og Claimants or otherwise have any obligations to Claimants under this Bond. § 11 The Sudety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. § 12 No suit or action shall be commenced by a Claimant under this Bond other than in a court of competent jurisdiction in the state in which the project that is the subject of the, Construction Contractis located or after the expiration of one year from the date (1) on which the Claimant sent a Claim to the Surety pursuant to Section S. 12 or 5.2, or (2) on which the last labor or service was performed by anyone or the last materials or equipment were furnished by anyone under the Construction Contract, whichever of (1) or (2) first occurs. If the provisions of this Paragraph aro void or pmiubltcd by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. § 13 Notice and Claims to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. Actual receipt of notice or Claims, however accomplished, shall be sufficient compliance as of the date received. § 14 When this Bond has been famished to comply with a statutory or other legal regai=cnt in tho location where the construction was to be performed, any provision In this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so famished, the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. § 15 Upon request by any person or entity appearing to be a potential beneficiary of this Bond, the Contractor and Owner shall promptly furnish a copy of this Bond or shall permit a copy to be made. § 16 Definitions § 16.1 Claim. A written statement by the Claimant including at a minimum: .1 the name of the Claimant; .2 the name of the person for whom the labor was done, or materials or equipment fiunished; .3 a copy of the agreement or purchase order pursuantlo, which labor, materials or equipment was furnished for use to the performance of the Construction Contract; A a brief description of the labor, materials or equipment R wished; .5 the date on which the Claimant last performed labor or last famished materials or equipment for use in the performance of the Construction Contract; .6 the total amount earned by the Claimant for labor, materials or equipment furnished as of the date of the Claim; .7 the total amount of previous payments received by the Claimant; and .8 the total amount due and unpaid to the Claimant for labor, materials or equipment furnished as of the date of the Claim. § 16.2 Claimant An individual or entity having a direct contract with the Contractor or with a subcontractor of the Contractor to fiunish labor, materials or equipment for use in the performance of the Construction Contract. Tho tern Claimant also includes any individual or entity that has rightfully asserted a claim under an applicable mcchanic% lien or similar statute against the reel property upon which the Project Is located. The intent of this Bond shall be to include without limitation in the terms "labor, materials or equipment" that part of water, gas, power, light, heat, oil, gasoline, telephone service or rental equipment used in the Construction Contract; architectural and engineering services required for performance of the work of the Contractor and the Contractor's subcontractors, and all other Items for which a mechanic's lien may be asserted in tho jurisdiction whero tho labor, materials or equipment were furnished. § 16.3 Construction Contract. The agreement between the {honer and Contractor identified on the cover page, including all Contract Documents and all changes made to the agreement and the Contract Documents. 3-21491AS 8H0 § 16.4 Owner Default. Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contractor to perform and complete or comply with die other material terms ofthe Construction Contract. § 16.6 Contract Documents. All the documents that comprise the agreement between the Owner and Contractor. § 17 If this Bond is issued for an agreement between a Contractor and subcontractor, die term Contractor in this Band shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. § 18 Modifications to this bond are as follows: THE PROVISIONS AND LIMITATIONS OF SECTION 255.05 FLORIDA STATUTES, INCLUDING BUT NOT LIMITED TO THE NOTICE AND TIME LIMITATIONS IN SECTIONS 255.05(2) AND 255.05(l 0), ARE INCORPORATED IN THIS BOND BY REFERENCE. (Space Is provided below for additional signatures of added parties, other than these appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) 11 M��. W.. � -. - W -W i � ME M Name and Title: / Address Ir -If(/ I S•21491AS 8110 Signature: Name and Title: Address POWER OF ATTORNEY UNITED STATES FIRE INSURANCE COMPANY PRINCIPAL OFFICE -MORRISTOWN, NEW JERSEY 1 C Q C C 1 JJ vv OO JJ KNOW ALL MEN BY THESE PRESENTS: That United States Fire Insurance Company, a corporation duly organized and existing under the laws of the state of Delaware, has made, constituted and appointed, and does hereby make, constitute and appoint: Kevin R. Waftowicz, David Turcios, John R. Neu, Daniel F. Oaks each, its true and lawful Attorney(s)-In-Fact, with full power and authority hereby conferred in its name, place and stead, to execute, acknowledge and deliver: Any and all bonds and undertakings of surety and other documents that the ordinary course of surety business may require, and to bind United StatesTire Insurance Company thereby as fully and to the same extent as if such bonds or undertakings had been duly executed and acknowledged by the regularly elected officers of United States Fire Insurance Company at its principal office, in amounts or penalties not exceeding: Seven Million, Five Hundred Thousand Dollars ($7,500,000). This Power of Attorney limits the act of those named therein to the bonds and undertakings specifically named therein, and they have no authority to bind United States Fire Insurance Company except in the manner and to the extent therein stated. This Power of Attorney revokes all previous Powers of Attorney issued on behalf of the Attorneys -In -Fact named above and expires on January 1, 2017. This Power of Attorney is granted pursuant to Article IV of the By -Laws of United States Fire Insurance Company as now in full force and effect, and consistent with Article III thereof, which Articles provide, in pertinent part: Article IV, Execution of Instruments - Except as the Board of Directors may authorize by resolution, the Chairman of the Board, President, any Vice -President, any Assistant Vice President, the Secretary, or any Assistant Secretary shall have power on behalf of the Corporation: (a) to execute, affix the corporate seal manually or by facsimile to, acknowledge, verify and deliver any contracts, obligations, instruments and documents whatsoever in connection with its business including, without limiting the foregoing, any bonds, guarantees, undertakings, recognizances, powers of attorney or revocations of any powers of attorney, stipulations, policies of insurance, deeds, leases, mortgages, releases, satisfactions and agency agreements; (b) to appoint, in writing, one or more persons for any or all of the purposes mentioned in the preceding paragraph (a), including affixing the seal of the Corporation. Article 111, Officers, Section 3.11, Facsimile Signatures. The signature of any officer authorized by the Corporation to sign any bonds, guarantees, undertakings, recognizances, stipulations, powers of attorney or revocations of any powers of attorney and policies of insurance issued by the Corporation may be printed, facsimile, lithographed or otherwise produced. In addition, if and as authorized by the Board of Directors, dividend warrants or checks, or other numerous instruments similar to one another in form, may be signed by the facsimile signature or signatures, lithographed or otherwise produced, of such officer or officers of the Corporation as from time to time may be authorized to sign such instruments on behalf of the Corporation. The Corporation may continue to use for the purposes herein stated the facsimile signature of any person or persons who shall have been such officer or officers of the Corporation, notwithstanding the tact that he may have ceased to be such at the time when such instruments shall be issued. IN WITNESS WHEREOF, United States Fire Insurance Company has caused these presents to be signed and attested by its appropriate officer and its corporate seal hereunto affixed this 5th day of August, 2015. ixsogµ UNITED STATES FIRE INSURANCE COMPANY t 4•/$��F�i Anthony R. Slimowicz, Senior Vice President State of New Jersey) County of Morris ) On this 5th day of August, 2015 before me, a Notary public of the State of New Jersey, came the above named officer of United States Fire Insurance Com r-aany, to me personally known to be the individual and officer described herein, and acknowledged that he executed the foregoing instrument and affixed the seal of United Stares Fire Insurance Company thereto by the authority of his office. SOMA SCALA NOTARY PUBLIC OF NEW JERSEY Sonia Scala (Notary Public) MY COMMISSION EXPIRES 3/2512019 I, the undersigned officer of United States Fire Insurance Company, a Delaware corporation, do hereby certify that the original Power of Attorney of which the foregoing is afull, true and correct copy is still in force and effect and has not been revoked. IN WITNESS WHEREOF, 1 have hereunto set my hand and affixed the corporate seal of United States Fire Insurance Company on theNday odo"f 9 20 I �' UNITED STATES FIRE INSURANCE COMPANY Sy , o., "o ...... .+' AI Wright, Senior Vice President FRONT PAGE OF PUBLIC PAYMENT BOND Florida Statute 255.05 Attached to and part of BOND NO. 6021078723 In Compliance with Florida Statutes Chapter 255.05 (1) (a), Public Work. All other Bond page(s) are deemed subsequent to this page regardless of any number (s) that may be pre-printed thereon. CONTRACTOR: Atlantic Roofing II of Vero Beach, Inc. 4020 43rd Avenue Vero Beach, FL 32960 (772) 492-8493 SURETY: United States Fire Insurance Company 305 Madison Avenue Morristown, NJ 07960 973-490-6600 AGENT: Nielson, Rosenhaus & Associates 8401 Lake Worth Road, Ste. 2-231 Lake Worth, FL 33467 561-713-1453 OBLIGEE: City of Sebastian 1225 Main Street Sebastian, FL 32958 772-589-5330 PROJECT: Sebastian Police Station Reroof Band No. 6021078723 Document A312 TM -2010 Conforms with The American Institute of Architects AIA Document 312 Performance Bond CONTRACTOR: (Name, legal status and address) Atlantic Roofing II of Vero Beach, Inc. 4020 43RD Avenue Vero Beach FL 32960 OWNER: (Maine, legal sraous and address) City of Sebastian 1225 Main Street Sebastian FL 32958 CONSTRUCTION CONTRACT Date: June 16, 2016 Amount S 70,595.00 SURETY: (Name, legal status and principal place of tininess) United States Fire Insurance Company 305 Madison Avenue Morristown NJ 07960 Mailing Address for Notices 305 Madison Avenue Morristown NJ 07960 This document has Important legal consequences. Consultation with an attorney Is encouraged with respect to lis completion or modification. Any singular reference to Contractor, Surely. Owner or other party shell be considered plural where applicable. Seventy Thousand Five Hundred Ninety Five Dollars and 00/100 Description Marne and location) Sebastian Police Station Reroof Located at 1225 Main Street Sebastian FL 32958 BOND Date: July 7, 2016 (Not earlier than Construction Contract Date) Amount $ 70,595.00 Seventy Thousand Five Hundred Ninety Five Dollars and 00/100 Modifications to this Bond: © None ❑ See Section 16 CONTRACTOR AS PRINCIPAL Company: (Corporate Seal) Atlantic Roofing 11 of Vero Beach, Inc. Sisnahue Name a-lu,117i" C and Title: r/r�� /46."''o SURETY Company: (Corporate Seal) United States Fire i`Insurance Company Signature: 12 --c_ `� Name Kevin R. Wojtowicz and Title: Attorney -in -Fact & FL Licensed Agent (Any additional signatures appear on the last page of this Perfennance Bond) (FOR 17YF0lbWA770NONLY — Maine, address and telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE: Nielson, Rosenhaus &Associates (Architect, Engineer orotherporty.) 8401 Lake Worth Road, Ste. 2-231 N/A Lake Worth FL 33467 561-713-1453 N/A 5-18521AS 8110 J 1 The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Omer for the performance of the Construction Contract, which is incorporated herein by reference. § 2 If the Contractor performs the Construction Contract, the Surety and the Contractor shall have no obligation under this Bond, except when applicable to participate in a conference as provided in Section 3. § 3 If there is no OwnerDefault under the Construction Contract, the Surety's obligation under this Boad shall arise after .1 the 0wner first provides notice to the Contractor and the Surety that the Owner is considering declaring a Contractor Default: Such notice shall indicate whether the Owner is requesting a conference among the Owner, Contractor and Surety to discuss the Contractor's performance. If the Owner docs not request a conference, the Surety may, within five (S) business days after receipt of the Owner's notice, request such a conference. If the Surety timely requests a conference, the Owner shall attend. Unless the Owner agrees otherwise, any conference requested under this Section 3.1 shall be held within ten (10) business days of the Surety's receipt of the Owner's notice. If the Owner, the Contractor and the Surety agree, the Contractor shall be allowed a reasonable time to perform the Construction Contract, but such an agreement shall not waive the Owner's right, if any, subsequently to declare a Contractor Default; .2 the 0%vncr declam a Contractor Default, terminates the Construction Contract and notifies the Surety; and .3 the Owner has agreed to pay the Balance of the Contract Price in accordance with the terms of the Construction Contract to the Surety or to a contractor selected to perform the Construction Contract. ' § 4 Failure on the part of the Owner to comply with the notice requirement In Section 3.1 shall not constitute a failure to comply with a condition precedent to the Surety's obligations, or release tate Surety from its obligations, except to the extent the Surety demonstrates actual prejudice. § S When the Owner has satisfied the conditions of Section 3, the Surety shall promptly and at the Surety's expense take one of the following actions: § 6.1 Arrange for the Contractor, with the consent of the Owner, to perform and complete the Construction Contract; § 6.3 Undertake to perform and complete the Construction Contract itself, through its agents or Independent contractors; § 6.3 Obtain bids or negotiated proposals from qualiCed contractors acceptable to the Owner for a contract for performance and completion of the Construction Contract, arrange for a contract to be prepared for execution by the Owner and a contractor selected with the Ownefs concurrence, to be secured with performance and payment bonds executed by a qualified surety equivalent to the bonds issued on the Construction Contract, and pay to the Owner the amount of damages as described in Section 7 in excess of the Balance of the Contract Price incurred by the Owner as a result of the Contractor Default; or § SA Waive its right to perform and complete, arrange for completion. or obtain a now contractor and with reasonable promptness under the circumstances: .1 After investigation, determine the amount for which it may be Rabic to the Owner and, as soon as practicable after the amount is determined, matte payment to the Owner, or .2 Deny liability in whole or in part and notify the Owner, citing the reasons for denial. § 6 If the Surety does not proceed as provided in Section S with reasonable promptness, the Surety shall be deemed to be in default on this Bond seven days ager receipt of an additional written notice from the 0wner to the Surety demanding that the Surety perforin its obligations under this Bond, and the Owner shall be entitled to enforce any remedy available to the Owner. If the Surety proceeds as provided In Section 3A, and the 0wner reRuscs the payment or the Surety has denied liability, in whole or in part, without further notice the Owner shall be entitled to enforce any remedy available to the Owner. S4862/AS ar10 § 7Ifthe Surety elects to act under Section 5.1, 5.2 or 5.3, then the responsibilities of the Surety to the Owner shall not be greater than those of the Contractor under the Construction Contract, and the responsbilIties of the Owner to the Surety shall not be greater than those of the Owner under the Construction Contrail. Subject to the commitment by the Owner to pay the Balance of the Contract Price, the Surety is obligated, without duplication, for the responsibilities of the Contractor for correction of defective work and completion of the Construction Contract; additional legal, design professional and delay coats resulting ftom the ContmeWs Default, and resulting horn the actions or failure to act of die Surety under Section 5; and liquidated damages, or If no liquidated damages arc specified In the Construction Contract, actual damages caused by delayed performance or non-performance of the Contractor. § 8 If the Surety elects to act under Section 5.1, 5.3 or 5.4, the Surety's liability is limited to the amount of this Bond. § 9 The Surety shall not be liable to the Owner or others for obligations of the Contractor that arc unrelated to the Conamcdon Contract, and the Balance of the Contract Price shall not be reduced or set off on account of any such unrelated obligations. No right of action shall accrue on this Bond to any person or cutity other than the Owner or its heirs, executors, administrators, successors and assigns. § 10 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. § 11 Any proceeding, legal or equitable, under this Bond may be instituted in any court of competent jurisdiction in the location in which the work or part of the work is located and shall be instituted within two years after a declaration of Contractor Default or within two years after the Contractor ceased working or within two years after the Surety refuses or falls to perform its obligations under this Bond, whichever occurs first. If the provisions of this Paragraph are void or prohibited by la%v, die minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. § 12 Notice to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. § 13 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision In this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incohporrcted herein. When so tirrnished, the intent is that this Bond shall be construed as a statutory bond and not as a common la%virond. § 14 Definitions § 14.1 Balance of the Contract Price. Tho total amount payable by the Owner to the Contractor under the Constriction Contract after all proper adjustments have been made, including allowance to the Contractor of any amounts received or to be received by the Owner in settlement of Insurance or other claims for damages to which the Contractor is entitled, reduced by all valid and proper payments made to or on behalfof the Contractor under the Construction Contract. §'14.2 Construction Contract. The agreement between the Owner and Contractor identified on the cover page, Including all Contract Documents and changes made to the agreement and the Contract Documents. § 14.3 Contractor Default. Failure of the Contractor, which has not been remedied or waived, to perform or otherwise to comply with a material term of the Construction Contra«. § 14.4 Owner Default Failure of the Owner, which has not been remedied or valved, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. § 14.6 Contract Documents. All the documents that comprise the agreement between the Owner and Contractor. § 16 If this Bond is issued for an agreement between a Contractor and subcontractor, the term Contractor In this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. S-1862/AS 8110 § 18 Modifications to this bond are as follows: (Space Is provided below for additional signatures ofadded parties, other then those appearing on the cover page) CONTRACTOR AS PRINCIPAL Company: (Corporate Seal) c c Signature: Nnme and 710c: Address S-1852/AS 8/10 SURETY Company: Signature: Name and Title: Address (Corporate Seal) THE PROVISIONS AND LIMITATIONS OF SECTION 255.05 FLORIDA STATUTES, INCLUDING BUT NOT LIMITED TO THE NOTICE AND TIME LIMITATIONS IN SECTIONS 255.05(2) AND 255.05(10), ARE INCORPORATED IN THIS BOND BY REFERENCE. Bond No. 6021078723 Document A312 TM —2010 Conforms with The American Institute of Architects AIA Document 312 Payment Bond CONTRACTOR: SURETY: (Marne, logal status and address) (Nanta, legal status and principal place of business) Atlantic Roofing II of Vero Beach, Inc. United States Fire Insurance Company 4020 43RD Avenue 305 Madison Avenue This document has Important legal Morristown NJ 07960 consequences. Consultation with Vero Beach FL 32960 Mailing Address for Notices an attorney Is encouraged with respect to its completion or 305 Madison Avenue modification. OWNER: Morristown NJ 07960 Any singular reference to (Name, legal status and address) contractor, Surety, Cwner or other party shall be considered Ci of Sebastian City plural where applicable. 1225 Main Street Sebastian FL 32958 CONSTRUCTION CONTRACT Date: June 16, 2016 Amount: a 70,595.00 Seventy Thousand Five Hundred Ninety Five Dollars and 00/100 Description: (Name and location) Sebastian Police Station Reroof Located at 1225 Main Street Sebastian FL 32958 BOND Date: July 7, 2016 (Nor earlier than Consinrction Contract Date) Amount: $70,595.00 Seven ty Thou san d Five Hundred Ninety Five Dollars and 00/100 Modifications to this Bond: F� None QX See Section IB CONTRACTOR AS PRINCIPAL Company: (Corporate Seal) Atlantic Roofing II of Vero Beach, Inc. Signatur<:: c � Name a1i,4111F a7 .I/G41 f and Tide: (Airy additional signatures appear on the last page of this Papnent Bond.) SURETY Company: (Corporate Seal) United States Fir Insurance Company Signature: I "L U Name Kevin R. Wojtowicz and Tide: Attorney -in -Fact & FL Licensed Agent (FOR INFOXW4TION ONLY —Nmne, address and telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE: Nielson, Rosenhaus &Associates (Archl(ect,Engineer orother party:) 8401 Lake Worth Road, Ste. 2-231 N/A Lake Worth FL 33467 561-713-1453 N/A S-2149/AS 8110 § 1 The Contractor and Surety, jointly and severally, bind themselves, their heir;, executors, administrators, successors and assigns to the Owner to pay for labor, materials and equipment liunished for use in the performance of the Construction Contract, which Is incorporated herein by reference, subject to the following terms. § 2 ifthe Contractor promptly makes payment of ail sums due to Claimants, and dcibads, indemnifies and holds harmless the Owner from claims, demands, liens or suits by any person or entity seeking payment for labor, materials or equipment furnished for use in the performance of the Construction Contract, then the Surety and the Contractor shall have no obligation under this Bond. § 3 If there is no Owner Default under the Construction Contract, the Surety's obligation to the Owner under this Bond shall arise after the Owner has promptly netWcd the Contractor and the Surety (at the address described in Section 13) of claims, demands, liens or suits against the Owner or the Owner's property by any person or entity seeking payment for labor, materials or equipment ftunished for use in the performance of the Construction Contract and tendered defense of such claims, demands, liens or suits to the Contractor and the Surety. § 4 When the Owner has satisfied the conditions in Section 3, the Surety shall promptly and at the Surety's expense defend, indemnify and hold harmless the Owner against a duly tendered claim, demand, lien or suit, § 5 The Surety's obligations to a Claimant under this Bond shall arise ager the following: § 5.1 Claimants, who do not have a direct contract with the Contractor, .1 have fumished a written notice of nen-payment to the Contractor, stating with substantial accuracy the amount claimed and the name of the party to whom the materials were, or equipment was, famished or supplied or for whom the tabor was done or performed, within ninety (90) days after having last performed labor or last furnished materials or equipment included In the Claim; and have sent a Claim to the Surety (at the address described In Section 13). § 8.2 Claimants, who arc employed by or have a direct contract with the Contractor, have sent a Claim to the Surety (at the address described in Section 13). § 0 If a notice of non-payment required by Section S.1.1 Is given by the Owner to the Contractor, that is sufficient to satisfy a Claimant's obligation to &mIsh a written notice of noa payment under Section S.M. § 7 When a Claimant has satisfied the conditions of Sections 5.1 or 5.2, whichever is applicable, the Surety shall promptly and ut the Surety's expense take the following actions: § 7.1 Send an answer to the Claimant, with a copy to the Owner, within sixty (60) days after receipt of the Cl" stating the amounts that arc undisputed and the basis fbr challenging any amounts that are disputed; and § 7.2 Pay or arrange for payment of any undisputed amounts. § 7.3 The Surety's failure to discharge its obligations under Section 7.1 or Section 7.2 shall not be deemed to constitute a % iver of defenses the Surety or Contractor may have or acquire as to a Claim, except as to undisputed amounts for which the Surety and Claimant have reached agreement. If, however, the Surety fails to discharge Its obligations under Section 7.1 or Section 7.2, the Surety shall indemnify the Claimant for the reasonable attorney's fees the Claimant incurs thereafter to recover any sums found to be due and owing to the Claimant. § 8 The Surety's total obligation shall not exceed the amount of this Bond, plus the amount of reasonable attorney's fees provided under Section 7.3, and the amount of this Bond shall be credited for any payments made in good fhith by the Surety. § 9 Amounts owed by the Owner to the Contractor under tho Construction Contract shall be used for the performance of the Construction Contract and to satisfy claims, If any, under any construction performance bond. By the Contractor furnishing and the Owner accepting this Bond, they agree that all funds tamed by the Contractor In the performance of the Construction Contract are dedicated to satisfy obligations of the Contractor and Surety under this Bond, subject to the Owner's priority to use the thnds for the completion of the work. . S -21491A3 8110 § 10 The Surety shall not be liable to the Owner, Claimants or others for obligations of the Contractor that are unrelated to the Construction Contract. The Owner shall not be liable for the payment of any costs or expenses of any Claimant under this Bond, and shall have under this Bond no obligation to make payments to, or give notice on behalf of, Claimants or otherwise have any obligations to Claimants under this Bond. § 11 The Surety hereby waives notice of any change, Including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. § 12 No suit or actioa shall be commenced by a Claimant under this Bond other than in a court of competent jurisdiction in the state in which the project that Is the subject of the Construction Contract is located or after the expiration of one year from the date (1) on which the Claimant scat a Claim to the Surety pursuant to Section S.1.2 or 5.2, or (2) on which the last labor or service was performed by anyone or the last materials or equipment were furnished by anyone under the Construction Contract, whichever of (1) or (2) first occurs. If the provisions of this Paragraph aro Vold or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. § 13 Notice and Claims to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. Actual receipt of notice or Claims, however accomplished, shall be suflicieat compliance as of the date received. § 14 When this Bond has been, furnished to comply with a statutory or other legal requirement In the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted heref um and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so fiunished, the intent Is that this Bond shalt be construed as a statutory bond and not as a common law bond. § 16 Upon request by any parson or entity appearing to be a potential bcnoficiary of oris Bond, the Contractor and Owner shall promptly furnish a copy of this Bond or shall permit a copy to be made. § 16 Definitions § 16.1 Claim. A written statement by the Claimant including ata'minimum: .1 the name of the Claimant; .2 the name of the person for whom the labor was done, or materials or equipment Pamished; .3 a copy of the agreement or purchase order pumant"to which labor, materials or equipment was furnished for use in the performance of the Construction Contract; A a brief description of the labor, materials or equipment furnished; .S the date on which the Claimant last performed labor or last furnished materials or equipment for use in the performance of the Construction Contract; .6 the total amount earned by the Claimant for labor, materials or equipment furnished as of the date of the Claim; .7 the total amount ofprevious payments received by the Claimant; and .8 the total amount due and unpaid to the Claimant for labor, materials or equipment famished as of the date of the Claim. § 16.2 Claimant. An Individual or entity having a direct contract with the Contractor or with a subcontractor of the Contractor to furnish labor, materials or equipment for use in the performance of the Construction Contract+ The term Claimant also includes any Individual or entity that has rightfully asserted a claim under an applicable mcchanicls lien or similar statut6 against the real property upon which the Project Is located The intent of this Bond shall be to include without limitation Ia the terms "labor, materials or equipment" that part of water, gas, power, light, heat, oil, gasoline, telephone service or rental equipment used In the Construction Contract; architectural and engineering services required for performance of the work of the Contractor and the Contractor's subcontractors, and all other items for which a mechanic's lien may be asserted in tho jurisdiction where the labor, materials or equipment were furnished. § 16.3 Construction Contract. The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and all changes made to the agreement and the Contract Documents. 8.21491AS 8110 § 16.4 Owner Default. Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms orthe Construction Contract. § 16.5 Contract Documents. All the documents that comprise the agreement between the Owner and Contractor. § 17 if this Bond is issued for an agreement between a Contractor and subcontractor, the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. § 18 Modifications to this bond are us follows: THE PROVISIONS AND LIMITATIONS OF SECTION 255.05 FLORIDA STATUTES, INCLUDING BUT NOT LIMITED TO THE NOTICE AND TIME LIMITATIONS IN SECTIONS 255.05(2) AND 255.05(l 0), ARE INCORPORATED IN THIS BOND BY REFERENCE. (Space Is pmvlded belewfor additional signatures ofadded parties, other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL Company: (Corporate Seal) Signature: ✓fes N--ne Address S-21491AS SMO SURETY Company: Signature: Nameand Address (Corporate Seal) POWER OF ATTORNEY UNITED STATES FIRE INSURANCE COMPANY 15866 PRINCIPAL OFFICE - MORRISTOWN, NEW JERSEY KNOW ALL MEN BY THESE PRESENTS: That United States Fire Insurance Company, a corporation duly organized and existing under the laws of the state of Delaware, has made, constituted and appointed, and does hereby make, constitute and appoint: Kevin R. Wojtowicz, David Turclos, John R. Neu, Daniel F. Oaks each, its true and lawful Attomey(s)-In-Fact, with full power and authority hereby conferred in its name, place and stead, to execute, acknowledge and deliver: Any and all bonds and undertakings of surety and other documents that the ordinary course of surety business may require, and to bind United States Fire Insurance Company thereby as fully and to the same extent as if such bonds or undertakings had been duly executed and acknowledged by the regularly elected officers of United States Fire Insurance Company at its principal office, in amounts or penalties not exceeding: Seven Million, Five Hundred Thousand Dollars ($7,500,000). This Power of Attorney limits the act of those named therein to the bonds and undertakings specifically named therein, and they have no authority to bind United States Fire Insurance Company except in the manner and to the extent therein stated. This Power of Attorney revokes all previous Powers of Attorney issued on behalf of the Attomeys-in-Fact named above and expires on January 1, 2017. This Power of Attorney is granted pursuant to Article IV of the By -Laws of United States Fire Insurance Company as now in full force and effect, and consistent with Article III thereof, which Articles provide, in pertinent part: Article IV, Execution of Instruments - Except as the Board of Directors may authorize by resolution, the Chairman of the Board, President, any Vice -President, any Assistant Vice President, the Secretary, or any Assistant Secretary shall have power on behalf of the Corporation: (a) to execute, affix the corporate seal manually or by facsimile to, acknowledge, verify and deliver any contracts, obligations, instruments and documents whatsoever in connection with its business including, without limiting the foregoing, any bonds, guarantees, undertakings, recognizances, powers of attorney or revocations of any powers of attorney, stipulations, policies of insurance, deeds, leases, mortgages, releases, satisfactions and agency agreements; (b) to appoint, in writing, one or more persons for any or all of the purposes mentioned in the preceding paragraph (a), including affixing the seal of the Corporation. Article 111, Officers, Section 3.11, Facsimile Signatures. The signature of any officer authorized by the Corporation to sign any bonds, guarantees, undertakings, recognizances, stipulations, powers of attorney or revocations of any powers of attorney and policies of insurance issued by the Corporation may be printed, facsimile, lithographed or otherwise produced. In addition, if and as authorized by the Board of Directors, dividend warrants or checks, or other numerous instruments similar to one another in form, may be signed by the facsimile signature or signatures, lithographed or otherwise produced, of such officer or officers of the Corporation as from time to time may be authorized to sign such instruments on behalf of the Corporation. The Corporation may continue to use for the purposes herein stated the facsimile signature of any person or persons who shall have been such officer or officers of the Corporation, notwithstanding the fact that he may have ceased to be such at the time when such instruments shall be issued. IN WITNESS WHEREOF, United States Fire Insurance Company has caused these presents to be signed and attested by its appropriate officer and its corporate seal hereunto affixed this 5th day of August, 2015. Fc�xsv UNITED STATES FIRE INSURANCE COMPANY Anthony R. Slimowicz, Senior. Vice President State of New Jersey) County of Morris ) On this 5th day of August, 2015 before me, a Notary public of the State of New Jersey, came the above named officer of United States Fire Insurance Company, to me personally known to be the individual and officer described herein, and acknowledged that he executed the foregoing instrument and affixed the seat of United States Fire Insurance Company thereto by the authority of his office. SONIA SCALA -'- j NOTARY PUBLIC OF NEW JERSEY Sonia Scala (Notary Public) '4P. MY COMMISSION EXPIRES 3/25/2019 I, the undersigned officer of United States Fire Insurance Company, a Delaware corporation, do hereby certify that the original Power of Attorney of which the foregoing is a full, true and correct copy is still in force and effect and has not been revoked. {, IN WITNESS WHEREOF, I have hereunto set my hand and affixed the corporate seal of United States Fire Insurance Company on the +'day of`)Bly, 20 "0 UNITED STATES FIRE INSURANCE COMPANY ef, •,,,aoeun ,...A...,!V.. �",�•° At Wright, Senior Vice President